Disclaimer

The information, services, and materials provided by Bricks Square Tech Infra ^TM (“Company”, “we”, “our”) through its website and Plot2Suite ecosystem are intended for general informational, professional, and service facilitation purposes only.

By accessing or using our services, you acknowledge and agree to the following:

Nature of Services

Bricks Square Tech Infra ^TM operates as a technology-driven construction solutions platform, offering services that include:

• Consultancy and advisory
• Design and planning
• Approval facilitation
• Project coordination and management
• Execution support (direct or through third parties)

The Company may act as a consultant, coordinator, facilitator, or execution partner, depending on the scope of engagement.

No Guarantee of Approvals

All approvals, permissions, and sanctions are subject to:

• Government authorities
• Regulatory bodies

The Company:

• Assists in documentation and coordination
• Does not guarantee approval, timelines, or outcomes

No Guarantee of Loan Sanction

Loan facilitation services (Plot2Loan) are provided through:

• Banking institutions
• DSA (Direct Selling Agent) associations

The Company:

• Assists in documentation and application processing
• Does not guarantee loan approval or disbursement

Third-Party Services Disclaimer

Certain services under the Plot2Suite ecosystem are delivered through:

• Empanelled partners
• Vendors and suppliers
• Labour contractors
• Technology providers

Accordingly:

• Execution is carried out by independent third parties
• The Company acts as a facilitator and coordinator

The Company shall not be held liable for:

• Delays, deficiencies, or failures by third-party service providers
• Quality or performance issues beyond its coordination role

Labour & Execution Disclaimer

Labour services may be provided through associated contractors on a square feet (SFT) package basis

The Company:

• Facilitates coordination and may charge service fees
• Does not directly employ all labour personnel

Design & Technical Disclaimer

All designs, drawings, and plans are:

• Conceptual and indicative in nature
• Subject to approvals, site conditions, and technical feasibility

Final execution may vary based on:

• Regulatory requirements
• Structural considerations
• Site conditions

Document & Information Disclaimer

The Company relies on documents provided by clients, including:

• Title deeds
• Encumbrance Certificates (EC)
• Approval documents

The Company:

• Performs preliminary review and facilitation only
• Does not certify legal ownership, title validity, or authenticity

Responsibility for document accuracy lies solely with the client.

Timelines Disclaimer

All timelines provided are: Indicative and non-binding

Delays may occur due to:

• Government processes
• Third-party involvement
• Site conditions
• Client-side delays

Financial & Cost Disclaimer

Project costs, estimates, and budgets are o Indicative and subject to change

Variations may occur due to:

• Market conditions
• Material costs
• Scope changes

Limitation of Liability

To the maximum extent permitted by law, Bricks Square Tech Infra ^TM shall not be liable for:

• Direct or indirect losses
• Delays or disruptions
• Approval rejections
• Loan denials
• Third-party performance issues
• Financial or commercial losses

Website Information Disclaimer

• Information on the website is provided for general guidance only
• The Company does not guarantee completeness, accuracy, or real-time updates

Professional Judgment

Clients are advised to:

• Exercise independent judgment
• Seek external legal, financial, or technical advice where necessary

Acceptance of Disclaimer

By using our website or engaging with our services, you:

• Acknowledge that you have read and understood this Disclaimer
• Agree to the limitations and conditions stated herein
• Accept the operational model of the Plot2Suite ecosystem